Chengdu Decoration Association's latest version of home improvement contract contract number: ________
Chengdu Family Room Decoration Project Construction Contract
Employer (Party A):
Contractor (Party B):
Chengdu Municipal Administration for Industry and Commerce, Supervisors, and Municipal Construction Commission Prepared for 2002
The Employer (hereinafter referred to as “Party Aâ€):
Address of residence:
Contact information:
Contractor (hereinafter referred to as "Party B"):
company address:
Business license number: Legal representative: Telephone:
This project designer: Phone:
Construction Team Leader: Phone:
In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, combined with the characteristics of the construction and decoration of family homes, the two parties shall, on the basis of equality, voluntariness, and consensus, carry out the decoration and decoration of the family room of Party A (hereinafter referred to as Related issues of Engineering), reached the following terms:
The first project overview
1.1 Project location: __________________________________________
1.2 Inside area: __________________________________________
1.3 Project Contents and Practices: See Design Drawings and Budget Statement for details
1.4 Project contracting methods: Both parties agreed to adopt the following ___ contracting methods.
(1) Party B works and packages.
(2) Party B has contracted and part of the materials, and Party A provides some materials.
(3) Party B contracted work, Party A package materials.
1.4 The project deadline _____day, the start date _____year_____ month _____day, the completion date _____ year __ month _____ days.
1.5 Contract price: The budget cost of this project is: RMB yuan, capitalized (RMB): ______________________ ___________; (To change the construction content, change the materials, the project cost is settled on a real basis).
Article 2 Project Supervision This project is conducted by the whole supervision, telephone:, Contact:.
Article 3 Construction drawings The two sides agreed to provide the following drawings in the following _____ ways:
(1) Party A shall design and provide construction drawings on its own. The drawings shall be in duplicate, Party A and Party B shall each make a copy.
(2) Party A entrusts Party B to design the construction drawings, the drawings are in duplicate, Party A and Party B each, and the design fee: RMB Yuan, capitalized (RMB): ____________________________Yuan, paid by Party A (this fee is included in the project In the price).
Article 4 Party A's Obligations
4.1 Before the start of construction, create conditions for Party B's admission construction. Including: removal of furniture, furnishings, furniture or furnishings that are not easy to move in the room, as well as collection and concealment, so as not to affect the construction principle;
4.2 Dismantle the original telephone equipment before construction; provide water, electricity and gas during construction;
4.3 Responsible for coordinating the relationship between the construction team and its neighbors;
4.4 It is forbidden to demolish the indoor load-bearing structure. If it is necessary to dismantle the non-load-bearing structure of the original building or change the location of the kitchen and toilet and equipment pipelines, it shall be responsible for handling the relevant approval procedures for the relevant departments; according to the regulations of relevant departments, Party A shall not The right to require Party B to move or reform the heating and gas pipelines;
4.5 During the construction period, Party A still needs to use the house in part, and is responsible for doing a good job of defending the site;
4.6 Participate in the supervision of project quality and construction progress. Responsible for material entry and acceptance.
Article 5 Party B Obligations
5.1 Strictly implement the safety construction operation rules, fire prevention regulations, construction specifications and quality standards during construction, and complete the project on schedule;
5.2 Strict implementation of the provisions on the management of the construction site shall not disturb the people and pollute the environment;
5.3 Protect the furniture and furnishings of the interior of the original room to ensure the smoothness of the indoor upper and lower pipelines;
5.4 Ensure the cleanliness of the construction site, and clean the construction site after the completion of the project;
5.5 Before Party A has officially provided the approval documents of the relevant departments, it is forbidden to alter the construction main body, load-bearing structure, heating and gas pipelines, etc. Otherwise, it shall bear the corresponding responsibilities;
5.6 Party B shall be responsible for the fines and compensation responsibilities caused by Party B's violation of the property management regulations during construction;
5.7 Party B's designers are responsible for providing relevant services such as consulting, design, and quotation to Party A. After the contract is signed, Party B assigns the project manager as the representative of the execution of the project construction. Party A shall contact the project manager of Party B regarding the project related matters to ensure the unified command and management in the project.
5.8 Party B shall calculate the quantity of work as accurately as possible. On the premise of no increase or decrease of project items and work contents, with the exception of hydropower reform and Party B's construction part outside purchasing main materials, the final price shall not exceed 5% of the budgeted cost, exceeding 5% of the budgeted cost. In part, Party B shall bear it.
Article 6 Project Changes
6.1 If the project and construction methods need to be changed, both parties shall agree on a signed change of design to clarify the relevant costs and duration of the project change. The verbal commitment or verbal agreement shall be deemed invalid; where Party A directly works with Party B All the consequences arising from the agreement to change the construction content shall be borne by Party A;
6.2 After the signing of the contract, Party A shall pay to Party B a change fee of 8% of the total amount of the reduction when the reduction of Party A's project exceeds 5% of the total project amount. If party B of the materials used by Party A has been ordered or shipped to the site, Party A shall pay for the consignment, loss, and return costs of the materials; if Party A requires the reduction of the construction project, Party A shall pay Party B the construction of the project. Fees, Material Fees, Management Fees and Demolition Fees;
6.3 Party A shall increase the construction project, and Party B shall construct it after receiving Party A's plan to increase 100% of the project.
Article 7 Provision of Materials
7.1 Materials and equipment provided by Party A; Party A shall notify Party B before the materials are shipped to the construction site. Both parties shall jointly accept and handle the handover procedures; if Party A fails to provide the materials or materials on time, the specifications and quality do not meet the design requirements. , thereby delaying the construction period or affecting the quality of the project, the responsibility shall be borne by Party A;
7.2 Materials and equipment provided by Party B; Party B shall notify Party A before shipment of the materials to the construction site and accept Party A's inspection; Party A shall have the right if the brand, specifications and quality of the materials provided by Party B do not match the quotations. Refusal to use, thereby delaying the construction period or affecting the quality of the project, the responsibility shall be borne by Party B;
7.3 Party A determines the material brand, specification, model or price standard, which Party B is responsible for purchasing for Party A. It can be used only after the materials are delivered to the construction site and approved by Party A. Party B collects Party A's material purchasing fee as material management fee (% of material) + material transportation fee (determined according to actual conditions); if return, replacement, and delay period are caused due to material quality problems in the construction process, Party A assumes responsibility;
7.4 Except as specified in the contract, hardware (door locks, handles, taps, etc.), stone, tiles, equipment, sanitary ware, lamps, kitchen cabinets, switch sockets, etc. shall be purchased by Party A and delivered to the site on time; if required Party B purchases and purchases purchase fees and transportation fees for purchased materials.
Article 8 Delays in duration
8.1 Delay in the completion date for the following reasons is confirmed by Party A. The duration of the construction period is correspondingly delayed:
(1) Changes in engineering quantities and design changes;
(2) Force majeure;
(3) Party A agrees with the other circumstances of the extension of the construction period.
(4) The delay of construction period caused by Party A's failure to participate in the phase acceptance.
8.2 If Party A fails to perform the work it is responsible for, which will affect the construction period, the construction period will be postponed. If the quality of the materials and equipment provided by Party A is unqualified and affects the quality of the project, Party A shall bear the cost of the rework and the construction period shall be postponed.
8.3 If the project cannot be completed on time due to Party B's supply or construction, etc., the construction period will not be postponed. If there is a problem with the quality of the project due to Party B's reasons, the rework cost shall be borne by Party B. The construction period shall not be postponed.
Article 9 Quality Standard
9.1 Both parties agreed that the construction quality of this project shall be accepted according to the following criteria:
(1) "GB50210-2001 Specification for Quality Acceptance of Building Decoration Engineering"
(2) "Chengdu Urban House Decoration Engineering Quality Acceptance Regulations"
(3) Other acceptance criteria:
9.2 When both parties dispute the quality of the project during construction:
(1) Mediation may be made to Chengdu Consumers Association Home Decoration and Complaint Center or Chengdu Building Decoration Association complaints;
(2) If you do not accept the mediation, the project quality inspection agency agreed by both parties will be responsible for the necessary expenses and the resulting losses. Both parties have responsibilities, and the two parties bear the responsibility according to their responsibilities.
Article 10 Project Acceptance and Warranty
10.1 The two parties agreed to check the quality of the project in the following stages during the construction process:
(1) Hidden project acceptance;
(2) Completion and acceptance.
Party B shall notify Party A to accept and accept it two days in advance. If Party A fails to participate in the acceptance on time after receiving the notice, Party B has the right to stop work, and the delays and other losses caused to Party B shall be borne by Party A;
10.2 After the completion of the project, Party B shall notify Party A of the acceptance. Party A shall organize the acceptance within two days after receiving the acceptance notice. The expiration shall be deemed as approval.
10.3 After the acceptance of the project is completed and the balance of the project is settled, Party B shall complete the transfer formalities with Party A and issue an engineering warranty to Party A to bear the warranty liability for the following year.
Article 11 Payment Methods for Construction Funds
11.1 The two parties agreed to pay the project payment in the following _____ ways:
(1) After the contract takes effect, Party A shall directly pay the project money to Party B as stipulated in the following table:
Payment times Payment time Payment amount First time: Second time: Third time: Contract signing date: Within 3 days after acceptance of concealed works: Within 4 days after completion acceptance: Paying: Yuan pays: Yuan pays the end of the project
The amount of progress paid for the first time is 50% of the construction portion of the decoration company;
The amount of progress paid for the second payment is 45% of the construction part of the decoration company plus the full amount of the contractor's purchasing materials for Party A;
(2) Other payment methods: _________________________________________________________
___________________.
11.2 After the acceptance of the project, Party B shall submit the project settlement to Party A within 2 days. If Party A does not have any objection within 2 days after receiving the data, it shall be deemed as agreeing and shall settle the project balance at the same time.
11.3 Party A shall send the project money directly to Party B's Finance Department. If Party A causes damages due to Party A’s direct payment of construction money to Party B’s construction personnel, Party A’s responsibility shall be the responsibility of Party A.
Article 12 Liability for breach of contract
12.1 Any party to the contract shall be liable for any financial loss or damages to the other party due to failure to perform the contractual stipulations or violations of national laws, regulations and relevant policies and regulations.
12. 2 If Party A fails to complete the acceptance procedure or fails to settle the balance and has not handed over the goods, Party A shall be deemed as qualified if it is used in advance or unauthorized use of the finished product. Therefore, Party A shall be responsible for the losses incurred, and shall be deemed as Party A shall automatically waive the warranty and Right to repair and Party B still has the right to recover the money;
12. 3 If for any reason the contract cannot be performed, the party shall promptly notify the other party to complete the contract termination procedure, and the responsible party shall compensate the counterparty for a penalty of 5% of the liquidated damages and other losses.
12.2 Due to Party B's reasons, the quality of the project cannot meet the quality standards agreed upon by both parties. Party B is responsible for repairs. The necessary repair costs shall be borne by Party B, and the duration of the project shall not be postponed.
12.3 Due to Party A or Party B's cause of the delay in the construction period, each delay on one day shall be regarded by the responsible party as 2% of the total construction cost as the penalty for breach of contract.
Article 13 Settlement of Contract Disputes The disputes arising from the performance of this contract shall be settled in the following _____________________________________________________
(1) Submit _________ __ Arbitration Commission Arbitration;
(2) To sue the people's court according to law.
Article 14 Specific Provisions
14.1 For the decoration works outside the urban area of ​​the project site, Party B shall pay a remote construction fee of 3%-10% of the total project cost;
14.2 During the construction period, Party A will give the key to the outhouse, ______, to Party B for safekeeping. After the project is completed and accepted, Party A shall be responsible for replacing the new lock.
14.3 During the construction period, Party B's daily working hours shall comply with the management requirements of the property management department of the residential area where it is located.
Article 15. Other matters stipulated: _______________________________________
______________________________________________________________________________
__________________________________.
Article 16 Supplementary Provisions
16.1 This contract shall become effective after both parties have signed (stamped) the contract and shall be terminated upon completion of the contract.
16.2 The project shall not be subcontracted after this contract is signed.
16.3 There are _______ copies of this contract and each party holds ______ copies.
16.4 The Annex to this contract includes construction drawings, quotation forms, budget quotation specifications and design changes. Covert acceptance visas are part of the contract and have the same legal effect as this contract.
Party A (signature): Party B (seal):
Legal representative:
Year Month Day Year Month Day
Construction Contract Decoration Decoration Interior Decor Home Decoration Furniture Decoration Project Budget Tile Specifications
Ultra Plantâ„¢ Grow Light offers One Chip Technology aimed to meet your indoor growing expectation such as improve plants' quality, increase yield, or better the margin, etc., all for helping you realize a higher return on your crops.
Ultra Plantâ„¢ Grow Light is combined our advanced All-In-One technology with patented optical design and customized light full spectrum supported from our experienced LED engineers, plant specialists and other partners working on horticulture.
From Ultra Plantâ„¢ APP, you are able to schedule the growing process including photoperiod, brightness and spectral in advance. The lighting system will help you grow smarter, easier and better.
Ultra Plantâ„¢ is the most versatile horticultural grow lighting fixture for indoor plants with flexible full spectrum, brightness control and uniform, wider light distribution, suitable for top lighting of all types of crops. No matter it applies to anywhere for any crop, Ultra Plantâ„¢ can do perfect work for you.
Far Red Grow Light,Far Red Led Grow Light,Far Red Light Plants,Far Red Led Grow Lights
Feton Corporation , https://www.ultraplantgrowlights.com